Terms of Sale

Last updated: 11 February 2026

1. Seller information

These Terms of Sale are issued by:

AS MUSIC, an EURL (single-member limited liability company), registered with the RCS Meaux under number 840 545 396, having its registered office at 15 allée des Fenaisons, 77600 Chanteloup-en-Brie, France, VAT number FR47840545396.

The Showcase Studio is a trade name operated by AS MUSIC.

Contact: hello@theshowcase.studio

2. Purpose & scope

These Terms of Sale govern the purchase and use of WordPress website templates and related installation/customization services sold through theshowcase.studio.

Our offers are intended exclusively for business customers (B2B). By placing an order, you confirm that you are acting in a professional capacity and agree to be bound by these terms.

3. Nature of the product & service

The Showcase Studio sells non-exclusive WordPress templates combined with a turnkey installation and customization service.

Unless explicitly stated otherwise, our offer is not a fully custom web design project. It is an adaptation of an existing template to your brand and content, within the limits described on each product page.

4. Ordering process

You select a template and complete your purchase on our website.

After payment, we send you a form to collect your brand assets, content, legal pages, and technical access details (domain, hosting and/or WordPress login, DNS if needed).

Once we have received all required elements, we schedule the installation and customization.

At the end of the process, we present the website for your review and provide the included round of minor adjustments within the agreed scope.

Communication. Unless otherwise agreed, project communication and approvals are handled in writing by email for clarity and traceability.

5. Price & payment

All prices are shown in euros and indicated as inclusive or exclusive of taxes as stated at checkout.

Payment is due in full at the time of order. We do not start any work until payment has been received.

The price shown on the product page includes the template license and the associated installation/customization service as described. It does not include your domain name, hosting, third-party plugin licenses, paid fonts, content creation, or any additional development/design work beyond the template.

6. Scope of customization

For each template, the product page specifies what is included (number of pages adapted, type of customization, etc.). Unless explicitly stated otherwise, standard customization includes:

Installation of the template on one WordPress website (one domain).

Setup of the main pages listed on the product page (e.g., Home, About, Services/Collections, Portfolio, Contact).

Application of your logo, brand colors and font choices within the limits of the template.

Insertion of your provided texts and images into the existing layouts.

Any request that significantly alters the structure, layout, or functionality of the template (new page types, new sections beyond scope, custom features, complex integrations, etc.) is considered additional work and will be subject to a separate quote.

7. Client responsibilities

You are responsible for:

Purchasing and configuring your own domain name and hosting.

Providing accurate, complete, and usable content (texts, images, legal pages, etc.).

Granting us the necessary temporary access to your hosting/WordPress environment to carry out the installation.

You represent and warrant that you hold the rights to all content you provide and that it does not infringe any third-party rights.

8. Timeline & delays

We aim to install and customize your website within the indicative timeline shown on the product page (typically 2–3 business weeks) after receiving all required content and access from you.

This timeline is an estimate and may vary depending on our workload and the complexity of your content. We will inform you if we expect any significant delay.

If you delay in providing content, access, or approvals, the delivery date will be postponed accordingly. We are not responsible for delays caused by late, incomplete, or unusable information.

9. Revisions & additional work

Each installation includes one round of minor adjustments after the first presentation of the site (text tweaks, image swaps, small layout refinements).

Any additional revision beyond this, or any request that significantly modifies the design, structure or functionality of the template, will be considered additional work and may be charged separately, after your approval of an estimate.

10. Intellectual property & license

We retain all rights to the original template design and underlying files.

Upon full payment, you receive a non-exclusive, non-transferable license to use the chosen template for one website (one domain) for your business or portfolio. Any multi-domain use requires additional licenses.

You own all content you provide (texts, logos, images you created, etc.). You are responsible for backing up your site and files after delivery.

11. Cancellations & refunds

If you wish to cancel before we start any work, contact us as soon as possible at hello@theshowcase.studio
. We may retain part of the amount paid to cover administrative and payment processing costs.

Once work has started (for example, installation of the template on your site, configuration, or customization), payments are non-refundable, except where mandatory law provides otherwise.

12. Technical environment & third-party services

Your website runs on WordPress and uses third-party tools such as Elementor (free version) and plugins. While we select tools we believe to be reliable, we are not responsible for:

Outages or issues caused by your hosting provider, domain registrar or email service.

Changes made by you or third parties after delivery.

WordPress/theme/plugin updates performed without proper testing or backups.

We cannot guarantee compatibility with every plugin, browser or device, but we design and test for modern, commonly used environments.

Unless explicitly stated, ongoing maintenance (updates, security, backups, long-term support) is not included.

13. Liability

To the maximum extent permitted by law, our liability under these terms is limited to the amount you paid for the template and associated service.

We are not liable for indirect, special, or consequential losses such as loss of revenue, profits, opportunities, reputation, or data.

14. Governing law & jurisdiction

These Terms of Sale are governed by the laws of France.

Any dispute arising out of or in connection with your purchase shall fall under the exclusive jurisdiction of the competent courts within the jurisdiction of the Paris Court of Appeal (France).